Podcasts about liquidated

This discussion is comprise three lectures covering the fundamental principles of contract law, from its origins and formation to the consequences of non-performance. The first lecture focuses on contract formation, detailing essential elements like mutual assent, offer, acceptance, consideration, capacity, and legality, as well as potential defenses. Building upon this, the second lecture explores contract interpretation, different standards for performance under common law and the U.C.C., the role of conditions, and the implications of breach, including anticipatory repudiation and the rights of third parties. Finally, the third lecture examines contract remedies, outlining legal damages (expectation, consequential, incidental) and equitable remedies (specific performance, injunctions, rescission), along with doctrines like restitution, quasi-contract, and defenses that can limit recovery.The four essential elements are mutual assent (offer and acceptance), adequate consideration, capacity, and legality.A bilateral contract involves an exchange of promises, becoming binding when promises are exchanged. A unilateral contract involves a promise in exchange for performance, becoming binding only upon completion of the requested act.The mirror image rule requires that an acceptance must exactly match the terms of the offer; any different or additional terms are considered a counteroffer, not an acceptance.The mailbox rule states that an acceptance is effective upon dispatch. Revocations, rejections, and counteroffers are effective upon receipt.Consideration is the value given in return for a promise, typically a bargained-for exchange of something of legal value.Promissory estoppel is an equitable doctrine where a promise is enforceable without consideration if the promisee reasonably relied on the promise to their detriment, and injustice can only be avoided by enforcing the promise.A void contract is unenforceable from the beginning, lacking legal force. A voidable contract is initially valid and enforceable but can be legally avoided or canceled by one of the parties.Defenses to contract formation include fraud, illegality, lack of capacity, mistake, duress, and undue influence.The primary purpose of expectation damages is to put the non-breaching party in the same economic position they would have been in had the contract been fully performed.Liquidated damages clauses are generally enforceable if actual damages were difficult to estimate at the time of contracting, the amount is a reasonable pre-estimate of likely loss, and the clause is not a penalty.

This lecture text explores contract interpretation, discussing how courts determine the meaning of agreements using the plain meaning rule and extrinsic evidence, such as course of performance, course of dealing, and usage of trade, while also considering the parol evidence rule. It then differentiates performance obligations under common law and the U.C.C., contrasting substantial performance with the perfect tender rule, and introducing the concept of conditions. The material further explains breach, including material versus minor breaches and anticipatory repudiation, before outlining the rights of third parties through assignment, delegation, and third-party beneficiary contracts, finally addressing ways performance may be excused due to impossibility, impracticability, or frustration of purpose.This conversation provides a comprehensive overview of contract law remedies, focusing on what happens when a contract is breached. It covers legal remedies, including expectation damages, incidental and consequential damages, the duty to mitigate, and equitable remedies like specific performance and rescission. The discussion also touches on restitution, quasi-contracts, liquidated damages, and the limitations that can affect the recovery of damages. The importance of understanding these concepts for law students and practitioners is emphasized throughout.TakeawaysUnderstanding remedies is crucial for contract law.Expectation damages aim to put the non-breaching party whole.Incidental damages cover reasonable costs incurred due to a breach.Consequential damages depend on foreseeability at the time of contracting.The duty to mitigate prevents unnecessary loss escalation.Equitable remedies are granted at the court's discretion.Specific performance is used when money damages are inadequate.Restitution prevents unjust enrichment, focusing on the defendant's gain.Liquidated damages must be reasonable and not punitive.Various doctrines can limit the recovery of damages.According to the plain meaning rule, courts interpret unambiguous contract language according to its ordinary meaning, without considering outside evidence.If contract language is ambiguous, courts may consider extrinsic evidence such as prior negotiations, drafts, industry standards, or other contemporaneous writings to determine the parties' intent.Course of performance refers to the parties' behavior under the current contract, while course of dealing refers to their conduct in previous contracts. Both provide insight into the parties' understanding of terms.The parol evidence rule's purpose is generally to prevent parties from using prior or contemporaneous oral or written statements to contradict or change the terms of a complete and final written contract.Common law substantial performance allows enforcement if the essential purpose is met with minor deviations, while the U.C.C.'s perfect tender rule requires goods to conform exactly to contract terms for the buyer to be obligated to accept them.Under the perfect tender rule, a seller might satisfy their obligation despite nonconforming goods by exercising their right to "cure" the defective tender within the contract performance period.A condition precedent is an event that must occur before a party is obligated to perform. An example from the source is a loan disbursement being conditioned on providing proof of income.A material breach is a serious violation going to the essence of the contract that excuses the non-breaching party's performance, while a minor breach is less significant and only entitles the injured party to damages.Upon anticipatory repudiation, the non-breaching party can treat it as a breach and sue immediately, suspend performance and wait, or urge performance and await retraction.An assignment is a transfer of rights under a contract, while a delegation is a transfer of duties. In a delegation, the original party typically remains liable unless a novation occurs.

This lecture series on contract law focuses on the remedies available when a contract is breached. It covers legal and equitable remedies, the measurement of damages, and the doctrines governing restitution and quasi-contract. The discussion emphasizes the importance of understanding these remedies for both academic analysis and practical application in resolving contractual disputes.TakeawaysUnderstanding remedies is essential for practical application.Expectation damages aim to place the non-breaching party in the position they would have occupied.Consequential damages must be foreseeable and communicated during contract formation.The injured party has a duty to mitigate damages.Specific performance is available when legal damages are inadequate.Restitution prevents unjust enrichment and measures the value of benefits conferred.Liquidated damages clauses are enforceable if they are a reasonable estimate of likely loss.Limitations on recovery can arise from contract terms and procedural doctrines.The landscape of contract remedies balances fairness and economic efficiency.Mastery of remedies informs how we enforce, draft, negotiate, and litigate contracts.contract law, remedies, damages, expectation damages, equitable relief, mitigation, restitution, quasi-contract, liquidated damages, breach of contract

Contract Law Fundamentals – Formation, Enforceability, and PerformanceThis lecture provides a comprehensive overview of contract law, a core subject in both law school and bar exam preparation. It examines how legally enforceable agreements are formed, what makes them valid or voidable, how obligations are performed or breached, and what remedies are available.FormationContract formation requires:Offer: A clear and definite promise showing willingness to enter into an agreement.Acceptance: Unequivocal assent to the terms of the offer, typically governed by the mirror image rule in common law and more flexibly under the Uniform Commercial Code.Consideration: A bargained-for exchange of value between the parties.Mutual Assent: Both parties must agree to the same terms under the objective theory of contract.Capacity and Legality: Parties must have the legal ability to contract, and the subject matter must be lawful.Defenses to FormationEven where the above elements are present, certain defenses may render a contract unenforceable:Misrepresentation (fraudulent or innocent)Duress and Undue InfluenceMistake (mutual or unilateral)UnconscionabilityLack of genuine assentThe Statute of Frauds requires certain contracts—like those involving real estate, suretyship, or long-term performance—to be in writing and signed.Performance and BreachUnder common law, parties must substantially perform their obligations unless there is a material breach.Under the UCC, the perfect tender rule applies, allowing buyers to reject goods that do not conform exactly to the contract.RemediesWhen breach occurs, the law aims to protect the expectation interest:Compensatory damages to put the non-breaching party in the position they expected.Consequential damages for foreseeable losses stemming from the breach.Liquidated damages if contractually specified and reasonable.Specific performance as an equitable remedy when monetary damages are inadequate.Restitution to prevent unjust enrichment.Third-Party RightsIntended beneficiaries may enforce contracts made for their benefit.Assignments and delegations allow parties to transfer rights and duties, with some limitations.A novation can relieve the original party of liability if the obligee agrees to substitute a new obligor.Policy ConsiderationsContract law balances freedom of contract with fairness, predictability, and market efficiency. The law adapts through judicial doctrines, statutory frameworks like the UCC, and evolving commercial practices, especially in digital transactions and standard form contracts.

This episode is a re-run. It was originally published in June 2023.Most people sign contracts without reading the fine print, but these will make you think twice. Don't sign another one until you hear these 5 shocking truths—listen up to learn more!Struggling with unfair contracts or slow payments in construction? With 6,000+ contracts reviewed and $20 billion in contracts managed, Quantum Contracts' proven framework is designed to help you negotiate fair contracts, secure faster payments, avoid disputes, and improve cash flow.Don't let contract issues hold you back—gain the confidence to focus on growing your business. Ready to take control and make more profit per project?Click here to IMPROVE your contracts using the Quantum Contract System: quantumcs.co/Yt2025Click here to BOOST your profit margins up to 15%: quantumcs.co/YtO3SimpleChangesClick here to GAIN expert advice weekly for FREE: quantumcs.co/YTNewsOptInTimestamps:(1:51) - The first thing is not having a reciprocal termination clause(2:34) - You need to make sure you have what's called reciprocal termination so that you can terminate them for default(4:13) - Having no cap on your liquidated damages means that if the delay is huge, those costs could just spiral and spiral and spiral and get bigger and bigger and bigger(4:40) - Consequential damages are consequential loss, which is essentially a loss of profit(4:48) - Liquidated damages is you compensating them for the costs of you being lateDISCLAIMER: The content of this podcast does not constitute legal advice, is not intended to be a substitute for legal advice, and can not be relied upon as such. You should seek legal advice or other professional advice in relation to any matters you or your business may have.Follow our Socials and let's get connected! ⤵️⁠⁠⁠⁠Facebook⁠⁠⁠⁠ | ⁠⁠⁠⁠LinkedIn⁠⁠⁠⁠ | ⁠⁠⁠⁠YouTube⁠⁠⁠⁠ | ⁠⁠⁠⁠Instagram⁠⁠⁠⁠ | ⁠⁠⁠⁠TikTok⁠⁠⁠⁠ | ⁠⁠⁠⁠Twitter

A crypto market bounce is coming but is it a trap? Many traders are jumping in, but only fools will trust it without looking deeper. In this video, Ran will reveal why this could be a fake-out, key warning signs, and smarter strategies. Don't get caught off guard and make mistakes or your crypto portfolio will pay the price! ___________________________________________

This episode is a re-run. It was originally published in June 2023.Liquidated damages: a contract term you can't afford to overlook. Find out how they work and why they're critical for project success – listen up!Struggling with unfair contracts or slow payments in construction? With 6,000+ contracts reviewed and $20 billion in contracts managed, Quantum Contracts' proven framework is designed to help you negotiate fair contracts, secure faster payments, avoid disputes, and improve cash flow.Don't let contract issues hold you back—gain the confidence to focus on growing your business. Ready to take control and make more profit per project?Click here to IMPROVE your contracts using the Quantum Contract System: quantumcs.co/Yt2025Click here to BOOST your profit margins up to 15%:quantumcs.co/YtO3SimpleChangesClick here to GAIN expert advice weekly for FREE: quantumcs.co/YTNewsOptInTimestamps:(3:28) - Liquidated damages is to reimburse the client for the cost of the delay to the construction project itself(4:38) - The key thing in consequential damages is your client, more often than not, is so big that his profit or his loss of profit could be the size of your company(5:20) - What can go wrong is they can hit you with liquidated damages and then they can also take you to court as well(5:35) - We want the liquidated damages clause to say that liquidated damages are the sole remedy for delay(6:19) - The biggest thing is capping how big the liquidated damages can beDISCLAIMER: The content of this podcast does not constitute legal advice, is not intended to be a substitute for legal advice, and can not be relied upon as such. You should seek legal advice or other professional advice in relation to any matters you or your business may have.Follow our Socials and let's get connected! ⤵️⁠⁠⁠⁠Facebook⁠⁠⁠⁠ |⁠⁠⁠⁠LinkedIn⁠⁠⁠⁠ |⁠⁠⁠⁠YouTube⁠⁠⁠⁠ |⁠⁠⁠⁠Instagram⁠⁠⁠⁠ |⁠⁠⁠⁠TikTok⁠⁠⁠⁠ |⁠⁠⁠⁠Twitter

Crypto Town Hall is a daily Twitter Spaces hosted by Scott Melker, Ran Neuner & Mario Nawfal. Every day we discuss the latest news in the crypto and bring the biggest names in the crypto space to share their opinions. ►►OKX Sign up for an OKX Trading Account then deposit & trade to unlock mystery box rewards of up to $60,000! 

Stephen Grootes speaks to Kabelo Khumalo, Companies & Markets reporter at Business Day, about the complex and far-reaching implications of the liquidation of Ithala Development Finance Corporation, which affects approximately 257,000 clientsSee omnystudio.com/listener for privacy information.

All Episodes are inside Skyway Central©Click here to access your Contracting Officer Podcast 2.0 License and start listening today!

The past 24 hours have been an absolute crypto bloodbath. More than $1 billion of long positions were liquidated when prices tanked and traders were "unprepared for the bad news." Spot Bitcoin ETFs saw record one-day outflows. So, why are most analysts calm and even positive? Aside from the chaos, the proposal to increase the Ethereum gas limit picks up steam, Craig Wright gets a one-year prison sentence suspended for two years for contempt of court, and the Tornado Cash co-founder wants his charges dropped following a verdict that OFAC "overstepped!" Yes, it's a busy episode today!Further reading:Crypto liquidations hit $1B as traders were ‘unprepared for bad news'Bitcoin ETFs hit by record $671.9M outflows in 1 dayCrypto chatter about ‘buying the dip' hits 8-month high: SantimentCraig Wright given suspended one-year sentence for contempt of court10% of Ethereum validators signal gas limit increaseTornado Cash dev wants charges dropped after court said OFAC ‘overstepped'Rise'n'Crypto is brought to you by Cointelegraph and is hosted and produced by Robert Baggs. You can follow Robert on Twitter and LinkedIn. Cointelegraph's Twitter: @CointelegraphCointelegraph's website: cointelegraph.comThe views, thoughts and opinions expressed in this podcast are its participants' alone and do not necessarily reflect or represent the views and opinions of Cointelegraph. This podcast (and any related content) is for entertainment purposes only and does not constitute financial advice, nor should it be taken as such. Everyone must do their own research and make their own decisions. The podcast's participants may or may not own any of the assets mentioned.

Click here to tweet VARMAGATE Part 2 NOW: https://ctt.ac/4Q66vJoin Mug Club for $10 off with Promo Code: UNDERCOVER https://mugclub.rumble.com/support/promo/UNDERCOVERMug Club Undercover releases PART 2 of the VarmaGate series today after NYC Covid Czar Dr. Jay Varma was fired by SIGA Technologies for comments he made regarding sex parties he attended while mandating Covid lockdowns, a Federal Bankruptcy Judge indicated Alex Jones' Infowars will be auctioned off piece by piece beginning in November to help satisfy his $1B+ judgment, the Haitian Bridge Alliance has filed criminal charges against Donald Trump and JD Vance, and so much more!GUEST: Nick Di PaoloSOURCES: https://www.louderwithcrowder.com/sources-september-25-2024Join Mug Club TODAY for $20 off with promo code LAWFARE: https://mugclub.rumble.com/support/promo/LAWFAREDOJ Chief of Public Affairs Admits Trump Indictments are a Politically Motivated ‘Perversion of Justice'; Reveals Lawfare Involved in Making Former President a ‘Convicted Felon' Backfired on Democrats; Claims His Former Colleague Alvin Bragg's Case is ‘Nonsense' and Alleges He Was ‘Stacking Charges'Send us a tip: LWCTips@ProtonMail.com

- InfoWars ordered LIQUIDATED by court order in effort to silence Alex Jones - Why Infowars transcends any studio assets or intellectual property - Special report on Alex Jones and the #InfoWars crew - Huge escalations in the Middle East as #Hezbollah bombs Israeli military base - Hezbollah unveils Fadi-3 rockets with greater range and explosive potential - Special report: God does NOT save #Israel - God destroys Israel and all other nations - Details on the Book of Revelation and 7 comet impacts - Interview with Jason Fyk on government #censorship collusion - Interview with Gerald Celente on financial Armageddon - Sermon #059 - Revelation Ch 13 - 16 - The Seven Trumpets and Seven Bowls describe the SAME SEVEN COMET IMPACTS that destroy all nations For more updates, visit: http://www.brighteon.com/channel/hrreport NaturalNews videos would not be possible without you, as always we remain passionately dedicated to our mission of educating people all over the world on the subject of natural healing remedies and personal liberty (food freedom, medical freedom, the freedom of speech, etc.). Together, we're helping create a better world, with more honest food labeling, reduced chemical contamination, the avoidance of toxic heavy metals and vastly increased scientific transparency. ▶️ Every dollar you spend at the Health Ranger Store goes toward helping us achieve important science and content goals for humanity: https://www.healthrangerstore.com/ ▶️ Sign Up For Our Newsletter: https://www.naturalnews.com/Readerregistration.html ▶️ Brighteon: https://www.brighteon.com/channels/hrreport ▶️ Join Our Social Network: https://brighteon.social/@HealthRanger ▶️ Check In Stock Products at: https://PrepWithMike.com

Sometimes an organization's backstory speaks volumes, which is definitely true of The Women's Foundation of the South (WFS). It was co-created into existence by a cohort of women, all accomplished grant makers of color who were compelled to build what the philanthropic sector lacked, a public foundation dedicated to the advancement of women and girls of color in the American south. They started to dream together in 2019 and launched in 2021 with Carmen James Randolph, its exceptional founder, at the helm. In this episode of Power Station, Carmen shares what it takes to start a foundation without major institutional donors, forging ahead through the Covid 19 pandemic and the devastation of Hurricane Ida, both of which exacerbated profound inequities in communities of color. These challenges shaped WFC's approach: investing in nonprofits and small businesses that serve those who are most vulnerable. She has garnered significant philanthropic support and is lifting up a powerful network of women who lead, without adequate recognition or resources, nonprofits in regions struggling with shattering maternal and infant mortality rates. As Carmen says, the WFC is exercising a vital tool of philanthropy, women's voice and leadership.

Welcome back to the Australian Property Investing Podcast Everything Property with your host David Hamilton. On today's episode, we are joined by Cian Brennan to break down everything you need to know about Building Contracts, whether that be for your next renovation, granny flat, duplex, townhouse or even bigger!During this chat, we cover:- How and why Cian first made the move to Australia- How he got started dealing with contracts and starting a business- The goal of the building contract- The 4 main areas you need to review when going through a building contract- The MOST important thing to remember when entering into a construction contract- Building brokers: What they do, the value they add and how they get paid- Questions to ask your builder- Liquidated damages: What they are and what you need to know- Consequential damages: What they are and what you need to know- Termination clauses- The cause of 90% of issues in construction contracts- How to handle changes in a construction contract (workflow)- Cost plus vs Lump Sum- Defects, retention and security- Plus much, much more!If you want to learn a bit more about the work Cian and his team does, head over to: https://quantumcontractsolutions.com/Don't forget to check out the summary post on our Instagram we just posted which covers what we discuss in this chat.Facebook: http://facebook.com/everythingproperty.auInstagram: http://www.instagram.com/everythingpropertyLinkedIn: http://linkedin.com/everythingpropertyWebsite (Coming soon)Disclaimer: The topics, conversation, opinions and discussion provided in this episode  are general in nature. As a listener you should not take or use the information discussed as financial advice. Everything Property and its associates recommend that you always engage in independent financial advice before making any investment or purchasing decision.

Nicholas Lorimer and Sara Gon discuss the looming liquidation of the South African Post Office unless it receives a R3.8 billion bailout within a month. They also discuss a school in Limpopo with 90 kids per class and the former chief engineer of PRASA going to jail. Website · Facebook · Instagram · Twitter

Joel and Phil dive in to liquidated damages and how the industry can avoid big payouts. GE Vernova is dealing with another offshore blade failure in the UK, and our thoughts on the latest renewable energy Instagram craze. And, a discussion on a very full eagle! If you have encountered metal staples in a GE 2.X-116 or 127 blades, reach out to Joel at joel.saxum@wglightning.com. There's still time to register for AMI Event's Wind Turbine Blade Conference in October 2-3rd! Click here - AMI Boston Wind Blade Conference Need low-cost lightning strike sensors for your turbine? Email Joel at Joel.saxum@wglightning.com. Sign up now for Uptime Tech News, our weekly email update on all things wind technology. This episode is sponsored by Weather Guard Lightning Tech. Learn more about Weather Guard's StrikeTape Wind Turbine LPS retrofit. Follow the show on Facebook, YouTube, Twitter, Linkedin and visit Weather Guard on the web. And subscribe to Rosemary Barnes' YouTube channel here. Have a question we can answer on the show? Email us! Pardalote Consulting - https://www.pardaloteconsulting.comWeather Guard Lightning Tech - www.weatherguardwind.comIntelstor - https://www.intelstor.com Allen Hall: All right. Really urgent news story here. A supposedly injured bald eagle. Now, remember that the bald eagle is America's bird. Is it America's bird or national animal? National mammal? And it's also like the national symbol too. It's a national symbol. There we go. All right. So a supposedly injured bald eagle, which is America's national symbol. Was rescued from a national park in Missouri and found it was acting like it was too injured to fly, but they took poor Eagle in and did an x ray on it and realized. That it was just full of raccoon. What? It was full? It had too much food? Yeah, it was found healthy, but engorged with raccoon. In other words, too fat to fly. Philip Totaro: Is there tryptophan in raccoons? Allen Hall: Oh, there may be. Joel Saxum: I'll tell you a fun fact about the eagle as the United States national symbol. Ben Franklin actually wanted it to be the turkey. And his reason. His reasoning was, eagles are actually scavengers and they eat dead things and turkeys don't. Allen Hall: Both of those birds are huge. If you've ever been anywhere near a bald eagle, they are massive creatures. I, the thing that bothers me about this is that eagle was living large, relaxing, chilling, and then somebody grabbed him! Somebody scooped him up and with the x ray in him, the next thing he knows, it's like he's waking up in a hospital and all he wanted to do was watch the Cowboys game, I'm Allen Hall and I'll be joined by the rest of the Uptime hosts after these news headlines. Denmark is making waves in the renewable energy sector with a massive 13 billion euro investment in offshore wind power. Aiming to boost capacity by 10 gigawatts across three areas. This ambitious plan, representing the largest tender for offshore wind power ever issued in Denmark, introduces a novel financing model where companies are required to make concession payments and co invest with the state. Which will retain a 20 percent stake in each project. This initiative is expected to create thousands of jobs with estimates suggesting that each gigawatt of offshore wind power could generate around 9, 500. Direct and indirect positions and require a capital investment of approximately 2. 1 billion euros. Beyond meeting national energy needs, the expanded capacity is set to position Denmark as a key exporter of electricity to neighboring countries. and a producer of green hydrogen. The European Commission's wind power package is breathing new life into the continent's wind industry with major players like Vestas and Siemens Energy expanding their operations. Vestas is establishing a new nacelle and blade factory in Poland, potentially creating over 1, 700 direct jobs by 2026. While Siemens Energy plans to hire around 4,

Joshua Frank, Co-Founder & CEO of The Tie, joins me to discuss the latest in crypto! He has the best insight in the industry. Chris Inks will join us in the second part to share some interesting trades in crypto and beyond.  John Frank: https://x.com/Joshua_Frank_ Chris Inks: https://twitter.com/TXWestCapital ►► COMING SOON!

Are you curious how a brand-new fishing team could win one of the most prestigious sailfish tournaments in their first year? In this episode, we sit down with Team Liquidated, the unexpected champions of the Quest for the Crest. Captain Danny and Owner Patrick share their journey from assembling their crew to battling seasoned veterans on the water. They reveal their strategic decisions during key moments, discuss the intense pressure of tournament fishing, and explain how they managed to stay ahead of the competition. The team also opens up about their pre-fishing routines, the importance of team chemistry, and their plans for defending their title. Whether you're a tournament angler or a weekend warrior, this conversation offers a rare glimpse into the world of high-stakes sailfish tournaments and the mindset required to come out on top. [00:00] - Introduction and team background [02:12] - Dust ‘em Off Tournament [05:37] - Putting the team together [09:43] - Sailfish Challenge Tournament and Pre-Fishing [14:58] - Final Sail Tournament strategy [20:17] - Battling Fish On for the title [25:43] - Winning moment and celebration [29:11] - Respect earned in the fishing world [33:24] - Plans for Marlin tournaments [36:52] - Offseason preparations and team changes [41:23] - Future goals and bigger fish [45:12] - Importance of consistent practice [48:37] - Closing thoughts and next season outlook

The Liquidators expedition is up and running in all of it's shooty, shooty glory. We're hard at working making the Euclid galaxy safe once more.

ICYMI: Hour One of ‘Later, with Mo'Kelly' Presents – A look at the importance of the 97th Annual 7-Eleven ‘Slurpee Day'…PLUS – Thoughts on California fast food franchisees cutting hours in response to the $20 per hour wage increase AND the impact of ‘Chicken Soup For The Soul' liquidating the company and all assets in their chapter 7 bankruptcy shift - on KFI AM 640…Live everywhere on the iHeartRadio app

It's not free speech and it's not the Deep State.    To advertise on our podcast, please reach out to sales@advertisecast.com or visit https://www.advertisecast.com/TheJeffWardShow

Dozens of the most popular conservative influencers spread video they claim shows Joe Biden pooping himself on stage, Dolly Parton attacked by CHUDs for being too good for this world, Alex Jones agrees to be liquidated, PLUS 50 other topics! If you enjoy my work, please consider supporting it by becoming a Patreon! Every little bit really helps. http://www.patreon.com/codcast We now have a P.O. Box so you can send us anything you want and we will unbox it live on the show. Send whatever you want to see me unbox to: Dusty Smith 1231 SUNSET DR STE 302 GRENADA, MS 38901-4025

Vice President Dr. Mahamudu Bawumia has announced that the Ministry of Finance is making arrangements to reimburse clients of companies liquidated by the Securities and Exchange Commission (SEC) during the financial clean-up exercise

Infowars host Alex Jones has one week left before he's required by the feds to cease all operations. Libertarian VP Candidate @TerMaatMike weighs in. @JustinJPetersen and @SteffiP4Liberty on Freedom Family Friday!

The prospects for troubled banking-as-a-service startup Synapse have gone from bad to worse this week after the United States Trustee filed an emergency motion on Wednesday. Learn more about your ad choices. Visit podcastchoices.com/adchoices

People blame Libs-of TikTok account after non-binary student in Oklahoma is reported dead a day after being beaten in school bathroom, Alex Jones is having is wealth liquidated by his victims, is Elon Musk's biggest fan actually Elon Musk himself? PLUS 50 other topics! If you enjoy my work, please consider supporting it by becoming a Patreon! Every little bit really helps. / codcast We now have a P.O. Box so you can send us anything you want and we will unbox it live on the show. Send whatever you want to see me unbox to: Dusty Smith 1231 SUNSET DR STE 302 GRENADA, MS 38901-4025 https://www.amazon.com/hz/wishlist/ls... Personal Amazon Wishlist in the unlikely case someone wants to send me something personally. All gifts unboxed during the show! https://www.amazon.com/hz/wishlist/ls... CODcast Discord server! https://t.co/SG3cuZ77Fi Direct tips: http://www.streamlabs.com/dustysmith or directly via paypal @ cultofdusty2@gmail.com Follow me for exclusive content on Twitch! / dustysmith Join this channel to get access to perks: / @cultofdusty Join this channel to get access to perks: / @cultofdusty

This episode is a re-run. It was originally published in October 2022. Construction contracts made clear! This podcast episode focuses on unraveling the mysteries of liquidated damages. Get the lowdown on what they mean and how they impact your projects. Listen in and level up your construction expertise! Construction Companies doing $5M+!

- Border convoy, Evergrande liquidation, and financial crisis. (0:02) - Financial instability and potential global economic collapse. (3:43) - German government's preparedness for war and lack of resources. (9:49) - Israeli military actions and their consequences. (14:41) - US military presence in the Middle East and drone strikes. (31:28) - Texas-Biden border dispute and insurance policies updating exclusions for war-related injuries. (35:56) - Health insurance and self-care. (41:20) - Western culture, politics, and identity. (51:42) - Political polarization and potential civil war in the US. (57:57) - Ukraine war and US foreign policy. (1:11:23) - US-Russia relations and nuclear arms control. (1:16:09) - Geopolitics and potential war threats. (1:28:20) - US foreign policy and energy impact on Europe. (1:34:11) - US-Iran relations, Yemen conflict, and Russia's role. (1:45:53) - ICC ruling and potential war crimes charges. (1:58:02) For more updates, visit: http://www.brighteon.com/channel/hrreport NaturalNews videos would not be possible without you, as always we remain passionately dedicated to our mission of educating people all over the world on the subject of natural healing remedies and personal liberty (food freedom, medical freedom, the freedom of speech, etc.). Together, we're helping create a better world, with more honest food labeling, reduced chemical contamination, the avoidance of toxic heavy metals and vastly increased scientific transparency. ▶️ Every dollar you spend at the Health Ranger Store goes toward helping us achieve important science and content goals for humanity: https://www.healthrangerstore.com/ ▶️ Sign Up For Our Newsletter: https://www.naturalnews.com/Readerregistration.html ▶️ Brighteon: https://www.brighteon.com/channels/hrreport ▶️ Join Our Social Network: https://brighteon.social/@HealthRanger ▶️ Check In Stock Products at: https://PrepWithMike.com

From the BBC World Service: Evergrande was once China’s biggest property developer. Now, a judge in Hong Kong has ordered the liquidation of the debt-laden real estate giant, but Evergrande says it’ll continue on China’s mainland. And French farmers take their fight over red tape and environmental policies to Paris. Plus, we hear how that city is tackling the problem of bed bugs ahead of the Summer Olympics.

From the BBC World Service: Evergrande was once China’s biggest property developer. Now, a judge in Hong Kong has ordered the liquidation of the debt-laden real estate giant, but Evergrande says it’ll continue on China’s mainland. And French farmers take their fight over red tape and environmental policies to Paris. Plus, we hear how that city is tackling the problem of bedbugs ahead of the Summer Olympics.

Guest: Caroline James| Advocacy coordinator at amaBhunganeSee omnystudio.com/listener for privacy information.

This episode is a re-run. It was originally published in October 2022. Did you know that consequential damages are one of the most common company-enders in construction? Equip yourself with the essentials and safeguard your projects from potential risks. Listen here! Construction Companies doing $5M+!

In this episode of The PDB Afternoon Bulletin: We dissect Israel's strategic and high-profile strike against Hezbollah, which resulted in the death of a high-ranking commander from the group's elite special operations unit, escalating regional tensions. We delve into the recent US Intelligence Assessment that has brought to light significant corruption within China's armed forces, prompting a major purge of the People's Liberation Army.   Please remember to subscribe if you enjoyed this episode of The President's Daily Brief.   Email: PDB@TheFirstTV.com Learn more about your ad choices. Visit megaphone.fm/adchoices

03rd Jan Crypto & Coffee at 8

Latest news from 03 December 2023, as reported in the Ukrainian media. Easy ways to support us: Subscribe to our Patreon to give monthly support https://www.patreon.com/highlightsfromukraine Send us a one-time 'thank you' tip via PayPal at: highlightsfromukraine@gmail.com Out YouTube channel: https://bit.ly/3oH111z Special thanks to our top Patreon supporters - Helena Pszczolko O'Callaghan, mattg629, krissi, Jared and Dick Warner!

In this insightful episode of The Site Shed, we tackle the pressing issue of labour shortage and how businesses can effectively hire during these challenging times. We dive deep into innovative hiring strategies, providing practical tips on navigating the labour shortage, attracting skilled employees, and ensuring their retention. Whether you're a small business owner or manage a large corporation, this episode is packed with valuable insights to help you overcome the hiring hurdles presented by the current labour market.Subscribe for more content on business strategies and workforce management. #LabourShortage #HiringStrategies #WorkforceDevelopmentWatch the video version of this podcast at https://youtu.be/ZttvJnt3O6QDiscussion Points: 01:12 Funny meet, virtual model, hiring, motivation, success.04:16 Liquidated damages led to business life low.06:55 Four parts to successful hiring process: finding candidates, vetting, hiring, and retention.11:38 Best marketers make great recruiters: speed matters.15:13 Deputise team, incentivise and increase applicants x4.16:33 Money-back guarantee, contractors prove doubters wrong.20:41 Onboarding: communicate, access, check-ins, raise, success.24:15 Flexible work hours, monthly company gathering28:47 Tools lost or broken. Pissed off, proud. Assessing achievements, seeking improvement.29:51 Growing business: evolving scorecards, better accountabilityResources:Contractor Consultants website - https://www.thecontractorconsultants.com/Get in touch with Matt at md@thecontractorconsultants.comReach out to Matt at 9786604389Get social with Matt at https://www.linkedin.com/in/matthewdibara/Read our blog on this podcast here:  https://www.thesiteshed.com/labour-shortage-recruitment-strategies-matt-dibara/  Have a conversation with us! Go to tradie.wiki/pod and book a call.Check this out: Get 30 guaranteed qualified leads in 90 days! Learn more here: https://tradie.wiki/tradie Learn more about the CRM that DOES IT ALL for your trade business! Just click on this link: https://tradiehub.net Join a global community of 6000+ trade professionals https://www.facebook.com/groups/TheSiteShed Connect with me on LinkedIn. For more podcast episodes, you can also visit our website. Thank you for tuning in! If you enjoyed this podcast and this series, please take 5 to leave us a review: Google Facebook Podcast

How do you calculate the value of liquidated damages? What do you ask for? How do you know what something is worth? According to contract expert Jeanette Nyden, “If you don't have a good risk analysis or cost analysts on the customer side, then you use formulas.” Jeanette shares what this could look like in this throwback episode of Negotiations Ninja!   

Technology professionals Rajeev and Tamara share their journey to financial freedom with Al Gordon. Struggling with ineffective retirement strategies, they turned to Lifestyles Unlimited in 2017 and learned how to leverage a cash-out-refi from their home equity and liquidated 401(k) and IRA accounts to passively invest $100k in real estate. Exceeding their first goal of $1 Million, what started out as passive investing has turned into real estate retirement! The lesson? Real estate investing is a proven path to retirement! Listen to these two inspiring individuals and learn how to take control of your financial future! Click to Listen Now

If you're reading this drop a Comment below

Welcome to Strategy Saturday; I'm Charles Carillo and today we're going to be discussing What are Liquidated Damages in Real Estate. Real estate contracts will always contain clauses that protect both the buyer, and the seller. In this episode, Charles discusses what liquidated damages are, and why they are included in most real estate contracts.   Connect with the Global Investors Show, Charles Carillo and Harborside Partners: ◾ Setup a FREE 30 Minute Strategy Call with Charles: http://ScheduleCharles.com ◾ FREE Passive Investing Guide: http://www.HSPguide.com ◾ Join Our Weekly Email Newsletter: http://www.HSPsignup.com ◾ Passively Invest in Real Estate: http://www.InvestHSP.com ◾ Global Investors Web Page: http://GlobalInvestorsPodcast.com/  

Today we are talking about the miners pivoting to AI and what's up with Bored Apes? Listener Survey https://docs.google.com/forms/d/e/1FAIpQLSdvmgIN36Uz8Xul73lNiLADM0vyUxHCuy5WKFDsgI1qiTznuw/viewform https://www.coindesk.com/business/2023/07/07/bitcoin-mining-is-a-game-of-survival-consolidation-and-potential-ai-diversification-bernstein/ https://www.coindesk.com/business/2023/06/30/applied-digital-stock-surges-12-after-announcing-its-third-ai-deal/ https://archive.ph/226PQ https://www.coindesk.com/business/2023/06/30/bitcoin-miner-hive-blockchain-touts-privacy-of-ai-models-running-on-its-gpus/ Matt Kimmell: https://twitter.com/MatthewKimmell Will Foxley: https://twitter.com/wsfoxley TIMESTAMPS: 00:00 Start 01:53 Miner's pivot to AI 12:08 Bored Ape MINE Start mining your own bitcoins with Compass. https://bit.ly/3CehBf1 WATCH https://youtube.com/c/CompassMining?sub_confirmation=1 LISTEN Apple Podcasts https://apple.co/3fNfrdi Spotify https://spoti.fi/3tSf9G1 Amazon https://amzn.to/3557cqg Anchor https://bit.ly/3rmb7UF Fountain https://bit.ly/3NeNTec RSS https://bit.ly/3chpULV  LEARN Every week, Compass sends a memo to over 18,000 professional miners and investors with the most important news and data in cryptocurrency mining. Get the free newsletter in your inbox too: https://bit.ly/3vOGzxD FOLLOW Twitter: https://twitter.com/compass_mining LinkedIn: https://www.linkedin.com/company/compassmining

Discover the 5 shocking things about construction that will put you ahead in the game of contracts! Tune in now!

Pay close attention to Liquidated Damages in your contracts! Do not disregard them! Construction Companies doing $5M+, watch this FREE Case Study on how Quantum has helped 8 Construction Companies sign lower risk contracts and boost cashflow & margin: ⁠⁠⁠⁠⁠https://quantumcs.co/casestudy-podcast⁠⁠⁠⁠⁠ If your business is making less than $5M, YOU are why I make all my materials FREE. Get more FREE Training & goodies here: https://constructionsecrets.io/ Timestamps: (3:28) - Liquidated damages is to reimburse the client for the cost of the delay to the construction project itself (4:38) - The key thing in consequential damages is your client, more often than not, is so big that his profit or his loss of profit could be the size of your company (5:20) - What can go wrong is they can hit you with liquidated damages and then they can also take you to court as well (5:35) - We want the liquidated damages clause to say that liquidated damages are the sole remedy for delay (6:19) - The biggest thing is capping how big the liquidated damages can be DISCLAIMER: The content of this podcast does not constitute legal advice, is not intended to be a substitute for legal advice, and can not be relied upon as such. You should seek legal advice or other professional advice in relation to any matters you or your business may have. Follow our Socials and let's get connected! ⤵️ ⁠⁠⁠⁠Facebook⁠⁠⁠⁠ | ⁠⁠⁠⁠LinkedIn⁠⁠⁠⁠ | ⁠⁠⁠⁠YouTube⁠⁠⁠⁠ | ⁠⁠⁠⁠Instagram⁠⁠⁠⁠ | ⁠⁠⁠⁠TikTok⁠⁠⁠⁠ | ⁠⁠⁠⁠Twitter

This episode is a re-run. It was originally published on June 2022. Stand out and make a big change for your company! Learn about liquidated and consequential damages, and transform your system. Take action now to make a difference! Construction Companies doing $5M+, watch this FREE Case Study on how Quantum has helped 8 Construction Companies sign lower risk contracts and boost cashflow & margin: ⁠⁠⁠⁠⁠https://quantumcs.co/casestudy-podcast⁠⁠⁠⁠⁠ If your business is making less than $5M, YOU are why I make all my materials FREE. Get more FREE Training & goodies here: https://constructionsecrets.io Timestamps: (2:26) - Liquidated damages are to reimburse them for the costs, the increased costs of construction because of your delay (3:48) - Agreeing to consequential damages is just something that you should always look for and make sure that you don't agree to (4;39) - Liquidated damages is a pre-agreed estimate to what those damages would be to save everyone the rigmarole of having to go to court (5:37) - If you see liquidated damages not filled out, that doesn't mean the liquidated damages are zero DISCLAIMER: The content of this podcast does not constitute legal advice, is not intended to be a substitute for legal advice, and can not be relied upon as such. You should seek legal advice or other professional advice in relation to any matters you or your business may have. Follow our Socials and let's get connected! ⤵️ ⁠⁠⁠⁠Facebook⁠⁠⁠⁠ | ⁠⁠⁠⁠LinkedIn⁠⁠⁠⁠ | ⁠⁠⁠⁠YouTube⁠⁠⁠⁠ | ⁠⁠⁠⁠Instagram⁠⁠⁠⁠ | ⁠⁠⁠⁠TikTok⁠⁠⁠⁠ | ⁠⁠⁠⁠Twitter

137. Welcome To The Alfalfa Podcast!

Welcome to the Alfalfa podcast

600,000 BTC Sell Order? Bitcoin to Crash to $5K? Michael Saylor to Get Liquidated? Crypto News ▬▬▬▬▬▬▬▬▬▬▬▬▬▬▬▬ Sign up for Token Metrics at https://tmt.link/tokenmetrics Sign up for our Weekly Newsletter at https://tmt.link/newsletter Podcast: https://tmt.link/podcast Research: https://tmt.link/research TV: https://tmt.link/tv ▬▬▬▬▬▬▬▬▬▬▬▬▬▬▬▬ Token Metrics Apparel: https://shop.tokenmetrics.com Crypto Investing Guide Audiobook: https://tmt.link/audible Crypto Investing Guide on Amazon: https://tmt.link/amazon Telegram Alerts Channel: https://t.me/TokenMetrics Telegram Discussion Group: https://t.me/TokenMetricsDiscussion Twitter: https://twitter.com/tokenmetricsinc Instagram: https://instagram.com/tokenmetrics TikTok: https://www.tiktok.com/@tokenmetrics Facebook: https://www.facebook.com/tokenmetrics LinkedIn: https://www.linkedin.com/company/toke... ▬▬▬▬▬▬▬▬▬▬▬▬▬▬▬ Token Metrics Media LLC does not provide individually tailored investment advice and does not take a subscriber's or anyone's personal circumstances into consideration when discussing investments; nor is Token Metrics Media LLC, registered as an investment adviser or broker-dealer in any jurisdiction. Information contained herein is not an offer or solicitation to buy, hold, or sell any security. The Token Metrics Media LLC team has advised and invested in many blockchain companies. A complete list of their advisory roles and current holdings can be viewed here: https://tokenmetrics.com/disclosures....

In this episode of UpOnly, Cobie & Ledger talk the rapid downfall of FTX and acquisition announcement by Binance. We're joined by the CEO of Wintermute, Jim Talbot, Gainzy, Do Kwon, and Martin Shkreli.